Tenders/Contracting specialized technical services for the elaboration of an Executive Project, including Basic Project, reports, technical specifications, budget spreadsheets, schedule, complementary studies, and other elements necessary for the future contracting of the automated irrigation system for the gardens surrounding the Headquarters building of the Court of Justice of the Federal District and Territories and for maintaining the water level of the ponds.

Open🇧🇷BrazilSupplies

Contracting specialized technical services for the elaboration of an Executive Project, including Basic Project, reports, technical specifications, budget spreadsheets, schedule, complementary studies, and other elements necessary for the future contracting of the automated irrigation system for the gardens surrounding the Headquarters building of the Court of Justice of the Federal District and Territories and for maintaining the water level of the ponds.

Auto-translated from Portuguese

Original title: Contratação de serviços técnicos especializados para a elaboração de Projeto Executivo, incluindo Projeto Básico, memoriais, especificações técnicas, planilhas orçamentárias, cronograma, estudos complementares e demais elementos necessários à futura contratação do sistema de irrigação automatizada destinado aos jardins que circundam o edifício Sede do Tribunal de Justiça do Distrito Federal e dos Território e à manutenção do nível dos espelhos d'água.

TRIBUNAL DE JUSTICA DO DISTRITO FEDERAL E DOS TERRITORIOS

Published: Oct 23, 2026

Updated: Oct 25, 2026

Source: PNCP Distrito Federal

About This Opportunity

This is a supplies contract in the architecture and engineering, urban development and housing and agriculture and food security sectors, with a focus on Irrigation. Located in Brazil, Latin America, this opportunity is open to firms and consortiums.

Published through PNCP Distrito Federal, a national government procurement portal. Public procurement tenders follow the country's national bidding regulations and may have specific eligibility and documentation requirements for the supply of goods in the architecture and engineering sector. Supply contracts typically require bidders to demonstrate product compliance with technical specifications, delivery capacity, and relevant certifications. Interested parties should review the full documentation on the original source before submitting their proposal.

Description

Original language: Portuguese

Contratação de serviços técnicos especializados para a elaboração de Projeto Executivo, incluindo Projeto Básico, memoriais, especificações técnicas, planilhas orçamentárias, cronograma, estudos complementares e demais elementos necessários à futura contratação do sistema de irrigação automatizada destinado aos jardins que circundam o edifício Sede do Tribunal de Justiça do Distrito Federal e dos Território e à manutenção do nível dos espelhos d'água. Órgão: TRIBUNAL DE JUSTICA DO DISTRITO FEDERAL E DOS TERRITORIOS Local: Brasília, Distrito Federal Modalidade: Dispensa

Data provenance

This notice is sourced from PNCP Distrito Federal and was originally published on October 23, 2026. Last refreshed 2 days ago. Original language: Portuguese. BidsFactory mirrors official procurement notices and links back to the source for full legal text.

About TRIBUNAL DE JUSTICA DO DISTRITO FEDERAL E DOS TERRITORIOS

TRIBUNAL DE JUSTICA DO DISTRITO FEDERAL E DOS TERRITORIOS has issued 116 procurement notices on BidsFactory, including 2 currently open and 79 awarded contracts. Activity concentrates in Education & Training, Information & Communication Technology, and Health & Medical. All notices are published for Brazil. Notices are distributed via PNCP Distrito Federal and Brazil PNCP. Most recent publication: October 26, 2026.

Frequently asked questions about this tender

Who is the contracting authority?

This notice was issued by TRIBUNAL DE JUSTICA DO DISTRITO FEDERAL E DOS TERRITORIOS in Brazil. The authority is responsible for evaluating bids, awarding the contract, and managing performance.

What type of contract is this?

This is a Supplies contract in the Architecture & Engineering Services sector. The classification helps bidders match the opportunity to their qualifications and registered scope of supply.

Where will the contract be performed?

The contract is for delivery in Brazil. Foreign bidders should review local registration, taxation, and any in-country presence requirements before submitting.

How can I submit a bid?

Visit PNCP Distrito Federal to access the full notice, required documents, and submission instructions provided by the contracting authority.