Tenders/Design services contract - TAE FRAMEWORK (Main Distribution Board – Accessible Ramp – Elevator – Compliance – Lighting of the Court of Economic Affairs)

Open🇫🇷FranceConsulting

Design services contract - TAE FRAMEWORK (Main Distribution Board – Accessible Ramp – Elevator – Compliance – Lighting of the Court of Economic Affairs)

Auto-translated from French

Original title: Marché de maîtrise d'œuvre - TRAME TAE (TGBT – Rampe PMR – Ascenseur – Mise en conformité – Eclairage du Tribunal des Affaires Economiques)

BIJPAC

Published: Oct 16, 2026

Updated: Oct 16, 2026

Source: TED - Tenders Electronic Daily (EU)

About This Opportunity

This is a consulting contract in the architecture and engineering sector, with a focus on Project Management. Located in France, Europe, this opportunity is open to firms and consortiums.

Published through TED - Tenders Electronic Daily (EU), a national government procurement portal. Public procurement tenders follow the country's national bidding regulations and may have specific eligibility and documentation requirements for consulting in the architecture and engineering sector. Consulting assignments are typically evaluated with a strong emphasis on the technical proposal, including the methodology and qualifications of key experts. Shortlisted firms may be invited to submit financial proposals in a second stage. Interested parties should review the full documentation on the original source before submitting their proposal.

Description

Original language: French

Marché de maîtrise d'œuvre composé de la mission de base augmentée des missions DIAG et EXE SYN dans le cadre des travaux de : - Remontée du TGBT et des autres installations techniques hors zone crues - Création d’une Rampe d’accessibilité PMR - Création d’un local technique également local poubelles - Création d’un ascenseur - Réfection d’un escalier et mise en conformité de l’accessibilité - Relamping du Tribunal de Commerce de Paris.

Data provenance

This notice is sourced from TED - Tenders Electronic Daily (EU) and was originally published on October 16, 2026. Last refreshed today. Original language: French. BidsFactory mirrors official procurement notices and links back to the source for full legal text.

Frequently asked questions about this tender

What type of contract is this?

This is a Consulting contract in the Architecture & Engineering Services sector. The classification helps bidders match the opportunity to their qualifications and registered scope of supply.

Where will the contract be performed?

The contract is for delivery in France. Foreign bidders should review local registration, taxation, and any in-country presence requirements before submitting.

How can I submit a bid?

Visit TED - Tenders Electronic Daily (EU) to access the full notice, required documents, and submission instructions provided by the contracting authority.

Who is the contracting authority?

This notice was issued by BIJPAC in France. The authority is responsible for evaluating bids, awarding the contract, and managing performance.